Welcome to Cura Group FL. These terms and conditions (the "Agreement") govern the provision of construction management services ("Services") provided by [Cura Group FL] (the "Company") to its clients (the "Client"). By engaging the Company’s services, the Client agrees to the following terms and conditions.

2. Scope of Services

The Company will provide construction management services, which may include but are not limited to:

• Project planning and scheduling

• Cost estimation and budget management

• Coordination with contractors, architects, and engineers

• Supervision of construction activities

• Quality control and compliance with safety regulations

• Procurement of materials and resources

• Documentation and reporting

Specific services to be provided will be outlined in the Service Agreement or Proposal for each project.

3. Fees and Payment Terms

• The Client agrees to pay the fees as outlined in the Service Agreement or Proposal.

• Payments must be made as per the schedule provided (e.g., upfront payment, milestone payments, final payment).

• Late payments may incur interest at [X]% per month, as permitted by law.

• The Company reserves the right to halt or delay services if payments are not made in a timely manner.

4. Project Timeline

• The Company will make every reasonable effort to complete the project within the timeline agreed upon in the Service Agreement or Proposal.

• Delays caused by factors beyond the Company’s control, such as weather conditions, material shortages, or acts of third parties, may result in an extension of the project timeline.

5. Client Responsibilities

• The Client must provide timely access to the site and all necessary information required to execute the project.

• The Client must ensure all necessary permits and approvals are obtained before project commencement unless otherwise agreed.

• Any changes or variations to the agreed scope of work must be communicated in writing and may result in additional costs and time extensions.

6. Changes to Scope of Work

• Any changes to the original scope of work must be requested in writing and agreed upon by both parties.

• The Company will issue a change order detailing the cost and time adjustments resulting from the change in scope.

• The Client must approve the change order in writing before any additional work is undertaken.

7. Warranties and Guarantees

• The Company warrants that all services will be provided with reasonable skill and care, and in accordance with industry standards.

• Any warranties on materials or workmanship provided by third-party contractors or suppliers will be passed on to the Client.

• The Company makes no other warranties, whether express or implied, including but not limited to warranties of merchantability or fitness for a particular purpose.

8. Liability

• The Company’s liability for any claim arising out of the provision of services will not exceed the total amount paid by the Client for those services.

• The Company will not be liable for any indirect, incidental, or consequential damages, including but not limited to loss of profits or business interruption.

• The Company will not be held liable for any defects in work performed by third-party contractors or any damage caused by delays outside its control.

9. Termination

• Either party may terminate this Agreement by providing [X] days' written notice.

• The Client will be responsible for payment for all work completed up to the date of termination.

• The Company reserves the right to terminate this Agreement immediately if the Client fails to make payments as agreed or breaches any other terms of this Agreement.

10. Force Majeure

The Company will not be held responsible for delays or failures in performance resulting from events beyond its reasonable control, including but not limited to natural disasters, acts of government, strikes, labor disputes, or material shortages.

11. Confidentiality

Both parties agree to keep any confidential information disclosed during the course of the project private and will not share this information with third parties without prior written consent.

12. Dispute Resolution

In the event of any dispute arising out of or in connection with this Agreement, both parties agree to attempt to resolve the dispute through good faith negotiation. If the dispute cannot be resolved, it will be submitted to mediation or arbitration as agreed by both parties before taking any legal action.

13. Governing Law

This Agreement will be governed by and construed in accordance with the laws of Broward County.

14. Entire Agreement

This Agreement constitutes the entire understanding between the Company and the Client concerning the subject matter hereof and supersedes all prior agreements, negotiations, and discussions.